Effective Date: April 15, 2016 | Last Updated: April 15, 2026
This document constitutes the complete Privacy Policy and Terms of Service (collectively, the "Agreement") governing your use of all websites, services, platforms, and properties owned and operated by Wildflower Development Group, LLC ("Wildflower," "Company," "we," "us," or "our"), including but not limited to wildflowerdev.com and all related subdomains.
By accessing our website, submitting any information through our forms, engaging our construction or development services, or otherwise interacting with Wildflower in any capacity, you ("User," "Client," "you," or "your") agree to be bound by the terms set forth in this Agreement. If you do not agree with any part of this Agreement, you must discontinue use of our services immediately.
Wildflower Development Group collects information to provide, improve, and protect our services. The types of information we collect include:
When you fill out contact forms, request access to our private registry, submit inquiries, apply for employment, or otherwise communicate with us, you may provide:
When you visit our website, we may automatically collect:
We may receive information about you from third-party platforms, including but not limited to social media networks, real estate listing services, advertising partners, credit reporting agencies (with your authorization), and public records.
Wildflower uses the information we collect for the following purposes:
We reserve the right to use aggregated, anonymized, or de-identified data for any lawful business purpose without restriction. Such data does not identify you personally and is not subject to the limitations of this Privacy Policy.
Wildflower Development Group does not sell your personal information to third parties. However, we may share your information in the following circumstances:
We retain personal information for as long as reasonably necessary to fulfill the purposes for which it was collected, maintain our business records, comply with legal obligations, resolve disputes, and enforce our agreements. Construction-related records, including contracts, correspondence, and warranty documentation, may be retained indefinitely as part of our permanent project archives.
You may request deletion of your personal information by contacting us at the address below. However, we reserve the right to retain certain information as required by law or for legitimate business purposes, including but not limited to warranty administration, dispute resolution, and regulatory compliance.
Our website uses cookies, web beacons, pixels, and similar technologies to enhance your browsing experience, analyze site traffic, and deliver targeted content. By continuing to use our website, you consent to our use of these technologies.
You may adjust your browser settings to refuse cookies; however, doing so may limit the functionality of certain features of our website. Wildflower is not responsible for any diminished experience resulting from your decision to disable cookies.
By accessing or using any Wildflower website, service, or property, you acknowledge that you have read, understood, and agree to be bound by these Terms of Service. These terms constitute a legally binding agreement between you and Wildflower Development Group, LLC.
All content on our website—including text, images, graphics, renderings, floor plans, pricing information, and site plans—is the exclusive property of Wildflower Development Group and is protected by applicable copyright, trademark, and intellectual property laws. You may not reproduce, distribute, modify, or create derivative works from any content without our prior written consent.
Pricing, availability, specifications, and floor plans displayed on our website are subject to change at any time without notice. All renderings and images are artistic representations and may not reflect the exact appearance of the final product. Wildflower makes no warranty that website content is complete, accurate, or current.
All construction projects undertaken by Wildflower Development Group are governed by separate, individually executed construction contracts. Nothing on our website or in this Agreement constitutes a binding offer to construct, a guarantee of pricing, or a commitment to specific timelines, materials, or specifications.
Wildflower reserves the right to substitute materials of equal or greater quality at its sole discretion. Construction timelines are estimates only and are subject to delays caused by weather, supply chain disruptions, labor availability, permitting, inspections, and other factors beyond our reasonable control. Wildflower shall not be liable for any damages, losses, or costs arising from construction delays.
All prices listed on our website, marketing materials, or communicated verbally are estimates and are subject to change until a formal purchase agreement or construction contract is fully executed by all parties. Wildflower reserves the right to adjust pricing based on material costs, market conditions, engineering requirements, and other factors at any time prior to contract execution.
Deposits, earnest money, and progress payments are governed by the terms of your individual construction or purchase agreement.
Wildflower Development Group provides a limited warranty on new construction as specified in your individual construction contract or warranty documentation. The scope, duration, and terms of the warranty vary by project and are set forth exclusively in the applicable warranty document provided at closing.
The warranty does not cover: normal wear and tear; damage caused by the homeowner, tenants, or third parties; damage resulting from failure to perform routine maintenance; alterations or modifications made without Wildflower's written approval; acts of God, natural disasters, or other force majeure events; cosmetic imperfections that do not affect structural integrity or functionality; or any item not expressly covered in the written warranty.
TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, WILDFLOWER DEVELOPMENT GROUP, ITS OFFICERS, DIRECTORS, MEMBERS, EMPLOYEES, AGENTS, CONTRACTORS, AND AFFILIATES SHALL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, PUNITIVE, OR EXEMPLARY DAMAGES ARISING OUT OF OR RELATED TO YOUR USE OF OUR WEBSITE, SERVICES, OR PROPERTIES, REGARDLESS OF THE THEORY OF LIABILITY.
IN NO EVENT SHALL WILDFLOWER'S TOTAL AGGREGATE LIABILITY TO YOU FOR ALL CLAIMS ARISING OUT OF OR RELATED TO THIS AGREEMENT, OUR WEBSITE, OR OUR SERVICES EXCEED THE LESSER OF (A) THE AMOUNTS ACTUALLY PAID BY YOU TO WILDFLOWER IN THE TWELVE (12) MONTHS PRECEDING THE CLAIM, OR (B) ONE THOUSAND DOLLARS ($1,000.00).
OUR WEBSITE AND ALL CONTENT, MATERIALS, AND INFORMATION PROVIDED THEREON ARE PROVIDED "AS IS" AND "AS AVAILABLE" WITHOUT WARRANTIES OF ANY KIND, WHETHER EXPRESS, IMPLIED, OR STATUTORY, INCLUDING BUT NOT LIMITED TO IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, TITLE, AND NON-INFRINGEMENT.
You agree to defend, indemnify, and hold harmless Wildflower Development Group, its officers, directors, members, employees, agents, contractors, and affiliates from and against any and all claims, damages, losses, liabilities, costs, and expenses (including reasonable attorneys' fees and court costs) arising out of or related to: (a) your use of our website or services; (b) your breach of this Agreement; (c) your violation of any law, regulation, or third-party right; or (d) any dispute between you and any third party related to a Wildflower property or service.
This Agreement and any disputes arising out of or related to this Agreement, our website, or our services shall be governed by and construed in accordance with the laws of the State of Wisconsin, without regard to its conflict of laws principles.
Any dispute, controversy, or claim arising out of or relating to this Agreement, or the breach, termination, or invalidity thereof, shall be settled by binding arbitration in Winnebago County, Wisconsin, in accordance with the rules of the American Arbitration Association. The arbitration shall be conducted by a single arbitrator, and the decision of the arbitrator shall be final and binding upon the parties. Judgment on the arbitration award may be entered in any court of competent jurisdiction.
YOU AGREE THAT ANY DISPUTE RESOLUTION PROCEEDINGS WILL BE CONDUCTED ONLY ON AN INDIVIDUAL BASIS AND NOT IN A CLASS, CONSOLIDATED, OR REPRESENTATIVE ACTION. YOU WAIVE ANY RIGHT TO PARTICIPATE IN A CLASS ACTION LAWSUIT OR CLASS-WIDE ARBITRATION AGAINST WILDFLOWER DEVELOPMENT GROUP.
Any claim or cause of action arising out of or related to this Agreement or your use of our services must be filed within one (1) year after the claim arose, or such claim is permanently barred.
Wildflower shall not be liable for any failure or delay in performance resulting from causes beyond our reasonable control, including but not limited to: acts of God, natural disasters, pandemics, epidemics, government actions or orders, war, terrorism, civil unrest, labor disputes, strikes, supply chain disruptions, material shortages, transportation failures, utility outages, extreme weather events, fires, floods, or any other event that is unforeseeable or beyond our ability to prevent.
This Agreement, together with any separately executed construction contract, purchase agreement, or warranty documentation, constitutes the entire agreement between you and Wildflower with respect to the subject matter hereof and supersedes all prior or contemporaneous communications, proposals, and agreements, whether oral or written.
If any provision of this Agreement is found to be unenforceable or invalid by a court of competent jurisdiction, that provision shall be limited or eliminated to the minimum extent necessary so that the remaining provisions of this Agreement shall remain in full force and effect.
Wildflower's failure to enforce any right or provision of this Agreement shall not constitute a waiver of such right or provision. Any waiver must be in writing and signed by an authorized representative of Wildflower.
You may not assign or transfer your rights or obligations under this Agreement without Wildflower's prior written consent. Wildflower may freely assign this Agreement or any of its rights and obligations hereunder without restriction.
Wildflower reserves the right to modify this Agreement at any time by posting the revised version on our website. Your continued use of our website or services after such modifications constitutes your acceptance of the updated terms. It is your responsibility to review this Agreement periodically for changes.
If you have any questions, concerns, or requests regarding this Privacy Policy & Terms of Service, please contact us:
By using our website, submitting information through any form, engaging our services, or otherwise interacting with Wildflower Development Group, you acknowledge that you have read, understood, and agree to be bound by this Privacy Policy & Terms of Service in its entirety.
© 2026 Wildflower Development Group, LLC. All rights reserved.