Terms and Conditions

Company Name: UNO Management LLC

These Terms and Conditions (“Agreement”) govern the services provided by UNO Management (“Company”, “we”, “our”, or “us”) to the client (“Client”, “you”, or “your”) and apply to all construction-related work, consultations, and interactions.

By hiring or engaging our services, you agree to these Terms and Conditions.

1. Services Provided

We offer residential, commercial, or industrial construction services, which may include:

  • New construction

  • Renovations or remodeling

  • Site preparation

  • Plumbing, electrical, HVAC, or subcontractor coordination

  • Project management and consultation

The exact scope of services will be detailed in a formal Proposal or Contract.

2. Estimates & Proposals

  • All estimates are valid for 30 days unless otherwise stated.

  • Any additional work not included in the original scope will require a Change Order and may affect pricing and timeline.

  • Prices are based on the best available information at the time of estimate. Market fluctuations in material or labor costs may require adjustments.

3. Project Timeline

  • Project start and completion dates are subject to weather, supply chain availability, permit approvals, and unforeseen site conditions.

  • Delays caused by the client (e.g., change orders, late payments, access issues) may result in schedule changes or additional charges.

4. Client Responsibilities

  • Provide safe and timely access to the site.

  • Ensure all permits, HOA approvals, or inspections are cleared (unless contracted with us).

  • Review and approve materials or design selections promptly.

  • Maintain clear and open communication.

5 Payments

  • A deposit (typically 30–50%) is required to begin work.

  • Payment schedule will be outlined in your contract (e.g., milestone-based, weekly, or upon completion).

  • Late payments may incur interest at 1.5% per month and could result in work stoppage.

6. Materials & Warranties

  • Materials will be of standard industry quality unless otherwise specified.

  • Manufacturer warranties will be passed to the client, where applicable.

  • Workmanship is warranted for [e.g., 1 year] unless specified in the contract.

  • Warranty is void if the client or third party alters the work post-completion.

7. Insurance & Liability

  • We carry general liability insurance and worker’s compensation.

  • We are not responsible for:

    • Pre-existing structural issues

    • Delays caused by third parties or government agencies

    • Damage caused by client negligence or failure to maintain the property

8. Termination

Either party may terminate this agreement with written notice:

  • Client will pay for all work completed and materials ordered up to the termination date.

  • Deposits may be non-refundable, depending on the stage of the project.

9. Dispute Resolution

In case of a dispute:

  • Parties agree to attempt informal resolution first.

  • If unresolved, disputes will be submitted to binding arbitration in accordance with the laws of [Your State/Country].

  • Legal fees may be assigned to the losing party in arbitration.

10. Force Majeure

We are not liable for failure to perform due to events beyond our control, including but not limited to:

  • Natural disasters (e.g., storms, earthquakes)

  • Acts of God

  • Material shortages

  • Labor strikes

  • Government actions or delays

11. Governing Law

These terms are governed by the laws of the State of [Your State], without regard to conflict of law principles.

12. Entire Agreement

This document, together with any proposal or signed contract, represents the entire agreement between the parties and supersedes any prior discussions, emails, or verbal communications.

13. Contact Information

UNO Management llc
3446 Haddonfield Rd Pennsauken New Jersey
Phone: 1-800-829-4933
Email:[email protected]


Navigating the complexities of general contracting with personalized guidance.

© 2025 UNO Management llc. All rights reserved.